TERMS OF SERVICE

Last Updated: January 24, 2026

1. Introduction

Welcome to SD ADUs (“Company,” “we,” “our,” or “us”). These Terms of Service (“Terms”) govern your use of our website and services related to manufactured home planning, permitting, and installation. By accessing our website or engaging our services, you agree to be bound by these Terms. Please read them carefully.

2. Services Provided

SD ADUs provides turnkey manufactured home development services in San Diego County. Our services include:

• Property analysis and feasibility reports
• Zoning research and site evaluation
• Manufactured home selection and planning
• Permit preparation and regulatory compliance
• Site preparation and utility coordination
• Manufactured home delivery and installation
• Project management and inspection coordination

By using our services, you agree to provide accurate property information and comply with all applicable local regulations related to land use and construction.

3. Client Responsibilities

You are responsible for providing accurate, complete, and truthful information during consultations, zoning research, permit applications, and project planning. Inaccurate or incomplete information may result in project delays, additional costs, or inability to proceed with services.

4. Intellectual Property

All content on this website — including text, graphics, design elements, logos, templates, and documentation — is the intellectual property of SD ADUs. Unauthorized copying, reproduction, distribution, or commercial use without written consent is strictly prohibited.

5. Payment and Fees

Service fees are outlined in individual project agreements and may include consultation fees, planning services, permitting services, site preparation, installation costs, and project management fees. Payment terms will be defined in your service contract. Failure to meet payment obligations may result in project delays or suspension of services.

6. Project Timelines

While SD ADUs works to meet estimated project timelines, completion dates may be affected by factors outside our control, including permitting agencies, utility providers, third-party contractors, material availability, or unforeseen site conditions. We will communicate schedule changes as they arise.

7. Cancellations and Project Modifications

Clients may request project modifications; additional costs may apply depending on project stage and scope changes. Project cancellations after work has begun may be subject to partial refunds based on completed services and incurred expenses.

8. Third-Party Services

SD ADUs may collaborate with third-party vendors, manufacturers, installers, engineers, or service providers. While we coordinate these services, SD ADUs is not responsible for liabilities, warranties, or performance issues arising directly from third-party providers.

9. Limitation of Liability

SD ADUs shall not be liable for damages exceeding the total value of the signed project agreement. This includes but is not limited to delays caused by permitting authorities, zoning changes, natural events, supply chain disruptions, or other circumstances beyond our control.

10. Governing Law

These Terms shall be governed by the laws of the State of California. Any disputes arising under these Terms shall be resolved through arbitration in San Diego County, California.

11. Changes to Terms

SD ADUs reserves the right to update or modify these Terms at any time. Updates will be posted on our website, and continued use of our services constitutes acceptance of revised Terms.

12. Contact Us

If you have any questions regarding these Terms or our services, please contact us:

SD ADUs
Email: info@sdadus.co
Phone: 619-494-2457
Website: www.sdadus.com